Terms & Conditions for Website
Please read our terms and conditions carefully before using this website. For the purpose of terms and conditions, “Us”, “Our” and “We” refers to EL PATRON RESIN (A.B.N. 81 607 908 904) and “You” and “Your” refers to all users of the site, the client, visitor, merchants and/or contributors of content. It also applies to orders made via telephone and email with the El Patron Resin customer service team.
By using our website and/or making a purchase with us, you are engaging in our “service” and agree to comply and be bound to our terms and conditions of use (“Terms and Conditions”, “Terms”, “Service”, including additional policies referenced herein.)
1 AMENDMENT OF TERMS
We reserve the right to change, modify, add or remove the terms and conditions at any time. You can review the most current version of the Terms and Conditions. Please check our terms regularly to ensure that you are aware of any changes.
If you choose to use our website and/or services then we will regard that use as conclusive evidence of your agreement and acceptance that these terms are your and El Patron Resin’s rights and obligations to each other.
2 LIMITATION OF LIABILITY
By using our website you are accepting that Elpatronresin.com is not legally responsible for any loss or damage you might suffer related to the use of the website. Your use of the information or materials on this website is entirely at your own risk and we shall not be liable. It is your own responsibility to ensure that any products, services or information provided from us meet your specific requirements. Such information and materials may not be current and/or include inaccuracies or errors and we exclude liability from such inaccuracies or errors. These errors may relate to product descriptions, pricing, promotion, offers, delivery charges, transit times and availability. We reserve the right to correct any errors, inaccuracies at any time without prior notice, including after you have submitted your order. Photographs of our products are provided for informational purposes only, and are not contractually binding.
You must be over 18 years of age to use this website or purchase any goods or services. You may not use our website for any illegal or unauthorised purposes. You may not violate any laws in your jurisdiction (including but not limited to copyright laws).
Elpatronresin.com reserves the right to exclude and not permit any person from using its website or contents contained on it. We reserve the right to refuse any order you place with us. In the case that we cancel or make a change to an order, we may attempt to email you or contact the number provided at the time the order was made. We reserve the right to not register a payment and thus not confirm an order, in particular but are not limited to the following reasons: problem with the order (abnormality, unavailability), the delivery address requested is outside the delivery areas, based on our sole judgement find the order appear placed by dealers, resellers or distributors. You may not use a false e-mail address, pretend to be someone other than yourself or mislead us or other parties as to the origin of any comment. You are solely responsible for any comments posted by you or any third-party. We hold the right to check ID and proof of address before dispatching any order to ensure security and protection against fraud.
3 DELIVERY OF PHYSICAL GOODS
El Patron Resin uses trusted couriers to deliver physical goods. Orders are not dispatched until full payment has been received and we are satisfied with the product. Please provide us with the correct phone number and address at the time of ordering. We will take accurate measures to display pricing of goods and services and delivery and other charges. All prices quoted are in Australian dollars and are inclusive of GST. Delivery charges will be applied after your product choices are validated and the order form has been completed. Please take note of delivery charges at checkout and make the payment in full in the prescribed conditions. El Patron Resin will not be held responsible and will not refund any payment if you have incorrectly provided details. If you wish to order again, it will be at your own expense. In the event where your overdue account is referred to a collection agency and/or law firm, you will be liable for all costs which would be incurred as if the debt is collected in full, including legal demand costs.
4 TRADE MARK PROTECTION
All trademarks are owned by El Patron Resin.
Except in the case of a license granted, you are prohibited from using or displaying (directly or indirectly), and agree not to use, display, or reference (directly or indirectly), any URL, trade name, trademark, logo, or branding of El Patron Resin or of any our affiliates, in any manner whatsoever (including, without limitation, in any meta-tags, search engine advertising, marketing or optimization, any other online or offline marketing or advertising, press releases, etc.) without the express, written permission of a represent ive of El Patron Resin or its applicable affiliate(s), which may be denied in the sole discretion of El Patron Resin or such Affiliates.
5 COPYRIGHT AND INTELLECTUAL PROPERTY
All copyright and other intellectual property are owned by El Patron Resin.
Nothing in these terms and conditions will function to transfer El Patron Resin’s Intellectual Property rights to any parties. We will retain exclusive interest in and ownership of our Intellectual Property on our website and social media channels. Any requests of usage of our copyright and other intellectual property must be pre-approved by a representative of El Patron Resin through a written agreement.
The website and any other content on social media channels are the intellectual property of and are owned by El Patron Resin. The structure, organization, and code of the website and other content contain valuable trade secrets and confidential information of El Patron Resin. Except as expressly stated herein, we do not grant you any intellectual property rights whatsoever in the website and on our social media and all rights are reserved by El Patron Resin. Any form, database, or software that is altered, conceived, made, or developed in whole or in part by El Patron Resin (including any developed jointly with you) during or as a result of our relationship with you shall become and remain the sole and exclusive property of El Patron Resin unless stated otherwise in a written agreement. You agree to make no claim in the rights or ownership of any such form, database or software. You agree to indemnify El Patron Resin for any third-party claims for infringement, misappropriation or other violation of any third-party’s intellectual property rights where such claims are made against El Patron Resin for forms, templates or exemplars created based upon material provided by you to El Patron Resin.
6 PAYMENT TERMS
Fees – You will pay all fees specified in our confirmed Order Forms. Except as otherwise specified herein or in a Order Form are (i) based on services, (ii) payment fees are non-cancellable if reserves services have been carried out, (iii) fees paid are non-refundable.
Changes in fees – We may change the fees for services at any time or impose additional fees or charges.
Such reasonable changes will be notified to you before the date of delivery and will be effective provided that there has been a mutual agreement to the changes in fees and once the invoice has been issued.
Invoicing and payment – You will pay us with valid and updated credit card information, or a valid purchase order or alternative document reasonably acceptable to us. If you provide us with credit card and/or other banking account information, you authorize us to charge such a credit card and/or banking account for all purchased services listed in the Order Form for our products and services subject to clause 3. Such charges shall be made in advance, either monthly, quarterly, annually or stated in the applicable Order Form. If the Order Form specifies that the amount will be charged in another form of payment, we will invoice you in advance and otherwise in accordance with the relevant Order Form. Unless stated otherwise in the Order Form, invoices charges are due 14 days from the invoice date. You are responsible for providing us complete and accurate billing information and notifying us of any changes to such information.
Overdue charges – If any invoiced amount has not been paid by the due date, then without limiting our rights or remedies, we will (i) charge a late fee of 10% of the outstanding balance per month, and/or (ii) condition future orders on shorter payment terms than those specified in this clause.
Suspension of service If any amount owed by you under this agreement or any other agreement for our services is 30 days or more overdue, we may, without limiting our rights and remedies, accelerate your unpaid fee obligations under such agreements so that all obligations become immediately due and payable, and suspend our services to you until such outstanding amounts have been paid in full. We will give you at least 7 days notice that your order is overdue before suspending services to you.
Terms & Conditions for Installations
Please read our terms and conditions carefully before entering into an agreement with our services. For the purpose of terms and conditions, “Us”, “Our” and “We” refers to EL PATRON RESIN (A.B.N. 81 607 908 904) and “You” and “Your” refers to all users of the site, the client, visitor, merchants and/or contributors of content. It also applies to orders made via telephone and email with the El Patron Resin customer service team.
By using our website and/or making a purchase from us, you are engaging in our “service” and agree to comply and be bound to our terms and conditions of use on our website, supplied documents (“Terms and Conditions”, “Terms”, “Service” and additional policies referenced herein. Definitions;
Business Days means any day other than a Saturday, Sunday, a NSW public holiday, or the NSW Government Christmas/New Year shutdown period (if declared).
Confidential Information means any technical, marketing, commercial, financial or other information of, about or in any way related to, El Patron Resin, including any information designated by El Patron Resin as confidential, which is disclosed, made available, communicated or delivered to the Client, but excludes information: (a) which is in or which subsequently enters the public domain other than as a result of a breach of these Condi- tions; (b) which the Client can demonstrate was in its possession prior to the date of this Contract; (c) which the Client can demonstrate was independently developed by the Client; or (d) which is lawfully obtained by the Client from another person entitled to disclose such information. Contract means the agreement between El Patron Resin and the Supplier for the supply and installation of the Goods as evidenced by these Conditions, the Purchase Order and the Proposal.
Defects Liability Period means the 12 month period commencing from the Acceptance Date.
Goods means the items (or any of them) to be supplied as described in the Proposal including installation materials, and confirmed in the Purchase Order.
GST Act means the A New Tax System (Goods and Services Tax) Act 1999 (Cth).
Installation Date means the date that the Works are to be completed, as set out in the Purchase Order.
Installation Works means all works necessary to install and commission the Goods on site.
Intellectual Property Rights includes all present and future copyright and neighbouring rights, all proprietary rights in relation to inventions (includ- ing patents), registered and unregistered trademarks, confidential information (including trade secrets and know how), registered designs and all other proprietary rights resulting from intellectual activity in the industrial, agricultural, literary or artistic fields.
Proposal means the proposal submitted by El Patron Resin in response to client briefs, including any subsequent amendments of the Proposal accepted by both parties being El Patron Resin and the client.
Purchase Order means the record generated by El Patron Resin in physical or electronic form which references the unique identifying number allocated by El Patron Resin to the provision of the Works under this Contract (“PO Number”).
Purchase Price means a fixed amount payable for the Works (excluding GST), as set out in the Purchase Order.
Works means the supply of Goods and Installation Works by El Patron Resin.
Clauses;
1 Supply and installation
(a) El Patron Resin agrees to:
(i) undertake the Works exercising the standard of care that would be expected of a contractor experienced and skilled in works of the nature of those to be undertaken by the Client under this Contract.
(ii) complete the Works by the Installation Date;
(iii) undertake the Works in accordance with this Contract and all applicable laws, business policies, guidelines, codes of conduct and the Purchase Order and these Conditions;
(iv) package all Goods to ensure maximum protection against damage during transit, delivery, loading and unloading.
(v) provide all relevant information (manuals, guides, instructions, procedures and financial documents) necessary for the proper and safe handling, transport, storage, use, operation, maintenance, repair and disposal of the Goods. If the Works are damaged after delivery where El Patron Resin is not liable for damages, El Patron Resin will offer repair for additional fees.
(vi) obtain, when necessary, for the benefit of the Client the benefit of any
manufacturer’s warranties provided for the Goods; and
(vii) provide all equipment, installation materials, labour and other things necessary to undertake the tasks and activities required to carry out the Works. (viii) Without in any way limiting subclause (a), El Patron Resin agrees to undertake the Works in conformity with their business policies and codes of conduct Framework, as well as any applicable government direction with respect to any act done in connection with the Works. The Client must inform El Patron Resin in writing at least 3 days prior to installation the policies and rules for site work. For example, some sites do not permit drilling through concrete. If the Client does not inform El Patron Resin of such policies and rules in relation to the Works installed on site, El Patron Resin will take that as approval and will not be liable for the changes.
(ix) El Patron Resin will not be held responsible for any loss and damages after the delivery of the Works. For example: Damages caused by visitors and animals or consumption of the materials .
2 Completion of Works
(a) El Patron Resin must complete the Works by the Installation Date.
(b) El Patron Resin must promptly notify the Client when the works have been completed.
(c) The client may inspect the Work and notify at least within 48 hours to send a written letter including photographs after installation completed to El Patron Resin of any concerns with the Works.
(d) If Works have been completed and confirmed by El Patron Resin (“Acceptance Date”), then the Defects Liability Period commences.
(e) If the Client (acting reasonably) considers that the Works have not been completed, they may notify within 48 hours to send a written letter including photographs after installation completed to El Patron Resin of those reasons and El Patron Resin will conduct an investigation and determine the necessary actions that must be taken to complete the Works. The Client must notify El Patron Resin if they believe the Works have not been completed, at no additional cost to El Patron Resin.
(f ) If El Patron Resin is or will be delayed in completing the Works by the Installation Date, including a delay being due to an event or circumstance beyond El Patron Resin’s reasonable control, they must notify the Client as soon as practicable, the cause of such delay and when it anticipates that it will be able to resume the Works. El Patron Resin will not be held responsible for any delays or costs arising from circumstances beyond its control.
(g) The Works are designed to last for life, backed by a 12-year warranty. Although colours may naturally fade over time due to the materials used, our commitment to durability ensures a long-lasting and high-quality finish. This warranty does not cover natural wear and tear, misuse, or damage caused by external factors (e.g., extreme weather, improper use).”
(h) In the first twelve months after the delivery date, upon written request by the Client, El Patron Resin may supply a maintenance polish and wax. El Patron Resin will conduct an examination of the Works and determine the necessary steps to be taken for the maintenance of the works. After twelve months of the delivery date, additional costs may apply.
(i) El Patron Resin will only inspect or view the finished floor from a standing position, as this is generally how you will be living on it. Minor marks or slight imperfections in the floor finish that can only be viewed from a crouching or kneeling position will not be considered defects.
3 No exclusivity
No provision of this Contract creates an exclusive agreement between the parties and El Patron Resin will always be entitled to offer goods and services to other clients from and contract with any other party it deems fit, for the provision of like works.
4 Ownership and risk
(a) Ownership in the Goods will pass to the Client upon delivery of the Goods to the site of installation.
(b) Risk in the Goods will pass to the Client when the Works are notified as complete by El Patron Resin under subclause 4(b).
5 Payment
(a) The client will only pay the fees outlined in the invoice following receipt by :
The client of a valid tax invoice, issued by El Patron Resin, together with such other information as the Client may reasonably require. The invoice must be sent to the Invoice Address specified in the Purchase Order.
(b) The Client must pay a 25% deposit of the fees is mandatory outlined in the invoice immediately for initiating sample production and confirming colors. The 50% down payment must be made to secure the booking and start date of the work. FINAL PAYMENT, 25% of the total amount, is required (7 DAYS BEFORE DELIVERY OF PROJECT). Prices do not include GST unless otherwise stated or extra fees ( Bank, Platforms, etc…). In the event that there is a change of mind, the Client must notify El Patron Resin in writing. If we have commenced ordering materials for the Works, we cannot offer a refund and the deposit will be forfeited to cover the expenditure of materials for the Works. (c) The Client will pay the outstanding amount of Purchase Price including GST to El Patron Resin within 7 days following receipt of an invoice issued by El Patron Resin that conforms with subclause (a,b).If payment is not fully received 7 days prior to the commencement of the job, it will be retained until the payment is made in full.
(d) The fees included in the receipt will include Purchase Price and GST and other additional costs for extra materials for the creation of installations, labour fees, delivery fees and other miscellaneous expenses. Before the Works begin, El Patron Resin will inform the Client of all costs incurred for the Works and Installation. (e) El Patron Resin acknowledges that any payment made to it by the Client is payment on account only and does not imply or constitute a waiver or release of the Client’s obligations under this Contract. (f ) Once installation materials for the Works have been ordered in, the Client will be charged full fees as outlined in the invoice. We do not offer refunds for change of mind once materials have been ordered in until delivery of the Works. (g) Any additional costs incurred due to unforeseen issues once the work has started will be communicated by El Patron Resin to the Client. The Client is obligated to pay these additional costs in order for the work to be completed successfully. If the Client fails to pay these additional costs, El Patron Resin reserves the right to stop the work until payment is made.(h) Overdue charges – If any invoiced amount has not been paid by the due date, then without limiting our rights or remedies, we will (i) charge a late fee of 10% of the outstanding balance per month, and/or (ii) condition future orders on shorter payment terms than those specified in this clause. Suspension of service If any amount owed by you under this agreement or any other agreement for our services is 30 days or more overdue, we may, without limiting our rights and remedies, accelerate your unpaid fee obligations under such agreements so that all obligations become immediately due and payable, and suspend our services to you until such outstanding amounts have been paid in full. We will give you at least 7 days notice that your order is overdue before suspending services to you. If payment remains 90–120 days past due, the account may be referred to a debt collection agency for recovery.
6 Defective Works
(a) If, during the Defects Liability Period, the Client identifies a defect in the Works (“Defective Works”), the Client may direct El Patron Resin to rectify these Defective Works, by way of repairing, replacing, modifying, performing or taking other actions acceptable to the Client (acting reasonably). The client must notify El Patron Resin of defects within 48 hours to send a written letter including photographs. Failure to do so within this time frame, the El Patron Resin will not take any responsibility carried on from this period and therefore will accept that the Works have no defects and will be over righted as satisfied with no errors.
(b) After inspection, if El Patron Resin agrees, it must, at its own cost, repair or rectify any Defective Works notified by the Client. (2.i.)
(c) The timing of the rectification work described in subclause (a) must be agreed with El Patron Resin, or may be specified by the Client (acting reasonably), before commencing the work.
(d) If El Patron Resin experiences delays or issues beyond our control to rectify the Defective Works within the time agreed or specified by both parties or by the Client under subclause (c) El Patron Resin must notify the client. The Client may engage another party to complete the repair at the Client’s own risk and expense.
(e) The Defects Liability Period will start from the date of the installation and any works repaired, replaced or made good by El Patron Resin will not mean that it will restart unless it is specified in a new agreement.
(f) El Patron Resin is not responsible for defects and imperfections in the floor caused by materials not provided by El Patron Resin itself (e.g., stickers, coins, metals, or any item the client wants to add). If this occurs, the warranty will be lost.
7 Supply of Goods (With Installation)
(i) El Patron Resin at all times, shall be suitably qualified and experienced, and shall exercise due skill, care and diligence in the carrying out and completion of the Works;
(ii) (Conflict) El Patron Resin and its employees, agents and contractors do not hold any office or possess any property, which are not engaged in any business or activity and do not have any obligations where by duties or interests are or might be created in conflict with or might appear to be created in conflict with its obligations under this Contract;
(iii) (IP) El Patron Resin is fully entitled to use and deal with any Intellectual Property Rights which may be used by it in connection with Works.
8 Indemnities
El Patron Resin must indemnify, and keep indemnified, its Clients and each of its employees, contractors and agents against any losses which any of them incurs or suffers in respect of:
(a) a negligent or wilful act or omission of El Patron Resin;
(b) loss or damage to any property;
(c) personal injury (including death or illness of any person); and
(d) claims that the Works breach the Intellectual Property Rights of any third party or any breach of confidence, arising out of or in connection with the performance of the Supplier’s obligations under this Contract, including failure by the Supplier to deliver the Goods.
9 Intellectual Property Rights
El Patron Resin grants to the client a non-exclusive, perpetual, royalty free licence to use any Intellectual Property Rights in relation to any Goods supplied to the extent necessary to allow the client the full use and enjoyment of those Goods and El Patron Resin must, upon request by the client, do all things as may be necessary (including executing any documents) to give full effect to such rights. The client must ensure all information is credited to El Patron Resin when it is used for any purpose including commercial and marketing usages.
10 Underground Locations & Hidden Services
(a)Prior to the El Patron Resin commencing any work the Client must advise the El Patron Resin of the precise location of all underground services on the Worksite and clearly mark the same. The underground mains and services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on the Worksite.
(b)Whilst El Patron Resin will take all care to avoid damage to any underground services the Client agrees to indemnify the Contractor in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 10.(a)
11 Risk
(a)If the El Patron Resin retains ownership of the Materials under clause 10 then:
Where the Contractor is supplying Materials only, all risk for the Materials shall immediately pass to the Client on delivery and the Client must insure the Materials on or before delivery. Delivery of the Materials shall be deemed to have taken place immediately at the time that either:
(i) the Client or the Client’s nominated carrier takes possession of the Materials at the El Patron Resin’s address; or
(ii) the Materials are delivered by El Patron Resin or the Contractor’s nominated carrier to the Client’s nominated delivery address (even if the Client is not present at the address)
(b)Notwithstanding the provisions of clause 11.(a) if the Client specifically requests El Patron Resin to leave Materials outside the El Patron Resin’s premises for collection or to deliver the Materials to an unattended location then such materials shall always be left at sole risk of the Client and it shall be the Client’s responsibility to ensure the Materials are insured adequately or at all. In the event that such Materials are lost, damaged or destroyed then replacement of the Materials shall be at the Client’s expense.
(c)The Client warrants that any structures to which the Materials are to be affixed are able to withstand the installation thereof and are of suitable capacity to handle the Materials once installed. If for any reason (including the discovery of asbestos, defective or unsafe structures or risk) that El Patron Resin reasonably form the opinion that the Client’s premises is not safe for the Works to proceed then El Patron Resin shall be entitled to delay the provision of the Works until El Patron Resin is satisfied that it is safe for the installation.
(d)El Patron Resin will not accept responsibility for any damage to the floor due to hydrostatic water problems, moisture vapour permeating the concrete slab, microenvironments caused by air-conditioning, heating or large expanses of glass windows without curtains or blinds.
Whilst El Patron Resin will take all due care to avoid contamination of the finished surface, El Patron Resin accepts no responsibility for contamination by natural contaminates such as dust or hair which may be present at the Worksite.
(e)El Patron Resin gives no guarantee (expressed or implied) as to the length of time the curing process will take and/or against cracking of concrete that may occur naturally in the Works such as:
(i) hairline cracking of paving and grout; or
(ii) damage caused by contact with chemicals, solvents, oils or any other substances; or
(iii) the effects by elements such as heat exposure or wet weather conditions that prolong the curing process
(f )El Patron Resin shall not be liable for any defect in the Works, if the Client does not follow El Patron Resin’s recommendation to:
(i) allow no foot traffic for a minimum of twenty four (24) hours and vehicles for a minimum of seven (7) days; and
(ii) place no heavy furniture on the Works area for a minimum of seventy two, (72) hours; and
(iii) protect the Works from inclement weather whilst the curing process is in progress. If the Client fails to protect the Works as per El Patron Resin’s recommendation, then any additional Works/Materials required will be charged as a variation.
(g)El Patron Resin will only inspect or view the finished floor from a standing position, as this is generally how you will be living on it. Minor marks or slight imperfections in the floor finish that can only be viewed from a crouching or kneeling position will not be considered defects.
(h)The Client acknowledges:
(i) that variations of colour and texture are inherent in concrete. El Patron Resin shall not be liable for any loss, damages or costs howsoever arising resulting from any variation of the colour or texture between different batches of product; and
(ii) that any slip resistant coating applied by El Patron Resin will assist in preventing slips and falls, however it will not completely eliminate such incidents from occurring. The treated surface may become slippy particularly after being exposed to wet, oily or greasy conditions. El Patron Resin can accept no liability for any injury to persons or any subsequent damage occurring as a result of a mishap whilst using the treated surface. It will remain the Clients responsibility to provide for their own safety and that of their family and visitors.
12 Worksite Access and Condition
El Patron Resinis not responsible for the removal of rubbish from or clean-up of the building/construction Worksite/s. All rubbish generated by El Patron Resin will be placed in a designated areas appointed by the Client but the responsibility of removal of same is the Client or the Client’s agent, unless otherwise agreed.
It is the intention of El Patron Resin and agreed by the Client that:
(a) the Clients shall ensure that the Contractor has clear and free access to the Worksite at all times to enable them to undertake the Works (including carrying out Worksite inspections, gain signatures for required documents, and for the delivery and installation of the Materials). El Patron Resin shall not be liable for any loss or damage to the Worksite (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of the El Patron Resin; and
(b) it is the Client’s responsibility to provide to El Patron Resin, while at the Worksite, with adequate access to available water, electricity, toilet and washing facilities
The Client agrees to be present at the Worksite when and as reasonably requested by El Patron Resin and its employees, contractors and/or agents.
13 Worksite Inductions
(a) in the event the Client requires an employee or sub-contractor of the Contractor to undertake a Worksite induction during working hours, the Client will be liable to pay the hourly charges for that period. If any induction needs to be undertaken prior to the commencement date then the Client shall be liable to pay the Contractor’s standard (and/or overtime, if applicable) hourly labour rate; or
(b) where El Patron Resin is in control of the Worksite, the Client and/or the Client’s third party contractors must initially carry out the El Patron Resin’s Health & Safety induction course before access to the Worksite will be granted. Inspection of the Worksite during the course of the Works will be by appointment only and unless otherwise agreed, in such an event the Client and/or third party acting on behalf of the Client must at all times be accompa- nied by El Patron Resin.
It is the Client’s responsibility to;
(a) protect the Works from vandalism or interference by any third party including the Clients pets or other animals; and
(b) remove all existing floor coverings, tacks and staples; and
(c) fully disclose any information that may affect the El Patron Resin’s installation procedures (including, but not limited to, disclosing known breaks or tears in the membrane, extensions of existing slabs, thickened beams, curing compounds that may have been used, or the use of concrete over 25mpa); and
(d) ensure the sub-floor is adequately ventilated and is structurally sound; and
(e) ensure that the levels of the sub-floor are satisfactory as the floor coverings can only follow the contours of the sub-floor and will not correct uneven- ness; and
(f ) remove all fragile items such as glassware, crockery, pot plants, furniture and ornaments. Breakages and damages are the responsibility of the Client. All care taken but no responsibility accepted by El Patron Resin in this regard; an
(g) provide adequate dust sheets to protect the Client’s furniture and décor. Flaking or crumbling walls should be temporarily covered by the Client, until the coatings are dry; and
(h) extinguish all naked flames prior to coating including, but not limited to, pilot lights, heaters etc.
(i) supplied products and materials, including but not limited to stickers and signage, must be compatible with epoxy resin.
El Patron Resin is not insured to remove furniture or fittings and will not do so, nor is El Patron Resin licensed to move gas or electrical appliances.
14 Warranties
(a) El Patron Resin warrants to the Client that:
(i) (Goods) the Goods:
(A) are new and fit for the purpose disclosed by the Client (or, if no purpose is stated, the purpose for which the Goods would ordinarily be used); (B) conform in all respects with the specification and industry standards, and are free from defects in materials or workmanship. (if stated);
(C) materials supplied by El Patron Resin are free from defects; and
(D) are of merchantable quality and comply with all laws.
12 Year Workmanship Warranty Terms and Conditions
Standard epoxy curing times
Foot traffic: 24 – 48 hours after completion.
Light furniture/equipment: 3 days after completion. Vehicle traffic: 7 days after completion.
After installation, all foot traffic must be kept off the floor for at least 24 hours to allow it to reach sufficient initial hardness. The floor will continue to harden for up to seven days, so the longer you can keep traffic and loads off, the better.
During the first seven days, do not allow any water, liquids or chemicals on the floor while it develops full resistance.
In order to protect the floor finish, install floor protectors or felt underneath the legs of heavy furniture, chairs and appliances to avoid scuffing and scratching.
Protect floor against heat sources and burns from heat, flames, sparks, cigarettes, matches or any other extremely hot surfaces.
Epoxy floors have great stain resistance. They are not affected by most household chemicals, however any spills should be cleaned up immediately and not be allowed to dry out on the floor. The longer the spill is left on the floor, the higher the risk of a stain occuring.
Do not use any other cleaning products apart from pH neutral cleaning detergents.
Wet/Dry microfibre flat dust mops are the most effective way to clean smooth epoxy floors.
General Ongoing Maintenance
Smooth Floors
Basic Good and Bad Practices
There are some basic good practices that can be followed to help prolong the life and aesthetics of a smooth floor.
Good practices include:
Sweep and mop floors on a regular basis. Regular cleaning will provide continued inspection to help detect and repair damage as soon as possible. Prepare a clean-up procedure to ensure exposure to spills is kept to a minimum. Smooth floors should be kept as dry as possible for the mainte- nance of the floor and safety of its users.
When moving equipment or furniture be sure to lift and not drag these items to prevent scratching. Smooth floors are susceptible to scuffing so be careful with the traffic allowed on these surfaces.
Bad practices to avoid:
Don’t use vacuum cleaners without brush attachment as they may scuff the surface.
Don’t use steam cleaners or boiling water as this may soften the floor. It is generally not necessary to clean with water above 60oC. Don’t wear footwear with metal tips or nails underneath.
If the floor is to handle vehicle traffic, avoid aggressively spinning the wheels, burnouts etc.
Anti Slip/ Textured Floors:
Basic Good and Bad Practices
There are some basic good practices that can be followed to help prolong the life and aesthetics of an anti-slip/textured floor.
Good practices include:
Sweep or flush/hose floors on a regular basis. More aggressive anti-slip surfaces (P4-P5) won’t be able to be mopped. Anti-slip floors, in particular, rely on regular cleaning to remove foreign material that can accumulate and reduce effectiveness.
Prepare a clean-up procedure to ensure exposure to spills is kept to a minimum. If the floor is exposed to aggressive industrial chemicals, an environmentally-friendly absorbent should be used to absorb the spill, followed by a chemical clean.
When moving equipment or furniture, be sure to lift and not drag these items to prevent scratching.
Bad practices to avoid:
Don’t use steam cleaners or boiling water as this may soften the epoxy floor. It is generally not necessary to clean with water above 60oC.
Don’t wear footwear with metal tips or nails underneath.
If the floor is to handle vehicle traffic, avoid aggressively spinning the wheels, burnouts etc.
What Is Not Covered By This Warranty
Flooring that is not installed or prepared by Epoxy Flooring Adelaide.
Improperly prepared floor surface where Epoxy Flooring Adelaide were not the party conducting the floor preparation.
Damage caused by subfloors and/or vapour barriers not installed by Epoxy Flooring Adelaide.
Delamination, blistering or peeling arising due to moisture issues or retention including hydrostatic or moisture vapour pressure.
Any damages to the coating by physical abuse, concrete failure, poor or weak concrete substrate, failure of the structure or substrate, vandalism, modifications to the substrate the coating is being applied, mechanical impact damage, damage caused by vehicles or heavy equipment, exposure to heat, sparks or flames, exposure to solvents and acids, windstorms, lightning, nails, screws, plant life, animal life, abuse or damage of the product by the customer, by other persons or any act of God.
This warranty does not apply to damage caused by a hydrostatic water problem, moisture vapour permeating the concrete slab, or exposure to either battery acid or brake fluid.
This warranty does not cover changes or oxidation of the coating as a result of normal weathering or atmosphere conditions.
This warranty does not apply to delamination caused by improper substrate conditions, or an internal failure of the substrate. Poor condition of the concrete, concrete failure or concrete strength.
This warranty does not apply to damage caused by cracks in the substrate prior to or occurring after the installation of the floor coating system that appear from ground shift and
expansion/contraction of the substrate, cracking due to substrate movement is not under warranty regardless of whether the same was repaired during original installation or not. There is no warranty for cracks or crack repair. Areas repaired under this warranty may vary in colour and texture from areas originally installed, which are not repaired. This limited warranty shall not apply in the case of improper substrate construction, exposure of the products to solvents and/or higher concentrations of acids other than that moisture from within, under or adjacent to the concrete
Atmospheric dust settles on uncured floor after reasonable precautions are taken to minimise the occurrence of this.
Insects, pets or other animals damaging the uncured floor surface.
Minor colour, shade or texture variations between sample or printed colour photography and the actual material.
Occasional (less than 1% of total area) dust specks, air bubbles, craters and minute amounts of extraneous materials in the surface. Surface defects that can only be seen from a certain angle or source of light.
Minor roller lines and transitions from applying the epoxy with a paint roller.
Flooring not maintained to the correct cleaning and maintenance as mentioned in this warranty.
Damage caused by accident, abuse or misuse of the floor.
Damage caused by vacuum cleaners, caster wheels or cutting from sharp objects.
Damage caused by abuse such as moving appliances across the floor without adequate protection.
Exposure to extreme conditions or temperatures.
Flooding caused by plumbing failures or natural causes.
Loss of gloss or scratching from general wear and tear.
Fading and discolouration naturally caused by direct sunlight exposure, UV lights or heat sources.
Other trades or construction damage after installation.
In The Event Of A Claim
In the event of a claim, the defect must be reported in writing to Epoxy Flooring Adelaide within 30 days of the discovery of the defect. After this time has elapsed, no further complaints will be accepted. Our staff must be given every opportunity to inspect the claimed defect.
In the case where a claim is accepted, Epoxy Flooring Adelaide will repair or replace the flooring of similar colour, pattern and quality for either the repair of the defective area or the replacement of the floor at our option depending on the claim. If the replacement or repair fails in the same manner a second time, the flooring or substrate conditions may not be acceptable for the installation of epoxy flooring. Consequential losses and any other costs are not covered by the warranty a second time.
Note – The services provided as part of the warranty do not extend the original warranty period. The warranty is not transferable and will apply to the first buyer only.
General Cleaning and Maintenance Guide
While your flooring system is extremely durable it must be allowed to cure prior to walking or driving on it to prevent any damage.
Standard epoxy curing times
Foot traffic: 24 – 48 hours after completion.
Light furniture/equipment: 3 days after completion. Vehicle traffic: 7 days after completion.
Sweep or vacuum
Sweeping your surface clean is an integral part of routine maintenance. Surface dirt and loose debris are unsightly and extremely abrasive. It should be removed effectively and regularly using a broom or vacuum. If you use a vacuum cleaner make sure it has a soft brush attachment. The normal hard plastic head on the vacuum could scratch your new floor over time. With outdoor areas you can simply hose it down or use a blower vac.
Cleaning
Cleaning your surface is important to maintain its visual appeal and remove surface contaminants that can be very abrasive. Cleaning can be completed by using a microfibre mop, floor mop or hose and brush/broom. A pH neutral cleaner should be utilised in combination with water and the above agitation methods. Ensure you follow all listed directions on your chosen cleaning product. For textured surfaces, a stiff broom may be used. Do not use abrasive or corrosive cleaners as they can cause discolouration or damage to your surface. On high- gloss surfaces, try to avoid using hard-bristled brooms and brushes as these may scratch the surface of the coating.
Stains and Spills
While your epoxy surface is resistant to staining and discolouration, all spills and other chemical contaminants should be cleaned from the surface as soon as reasonably possible. This will reduce the possibility of staining as prolonged or extended exposure to some chemicals may result in staining of your surface, especially those that are acidic or corrosive. Staining is only aesthetic and does not affect the mechanical properties of the surface.
High Gloss surfaces such as Metallic Marble, Plain Epoxy or Flake finishes are especially susceptible to scuffing and scratching due to their gloss appearance and the abrasiveness of floor grit and dirt. It is recommended that clean regularly in order to maintain the floor in its original high-end and high-gloss appearance. It is not recommended to move heavy furniture without mechanical assistance and felt furniture feet should be used on all furniture where it intends to be moveable, such as tables, chairs and stools. Follow these simple cleaning methods to ensure your epoxy floor stays looking new for many years to come.
High Gloss Surfaces
Your new epoxy floor is hard-wearing, easy to clean and typically does not require any ongoing maintenance. However, In order to keep your surface looking new you should follow a regular cleaning regime. This will reduce ongoing wear and tear.
Terms and Conditions Updates
This Policy may change from time to time and is available on our website. Terms and Conditions
If you have any queries or complaints about our Terms and Conditions please contact us at: enquiries@elpatronresin.com